Before everyone looked at it, I still have a few words to say:
First, the contract is not very professional, provided to everyone, only for your reference.
Second, the contract is only a contract, do not place too high expectations on it, if you are looking for a bad decoration team, do not expect a contract will allow them to do a good job, so the most critical thing is to select the team .
Third, welcome genuine connoisseurs to make criticisms, or which enthusiastic personages in the industry can revise and perfect it, and provide new students with a true contractual clean contract model.
IV. Annex I and Annex 2 of the contract I omitted because it is something in my family that makes no sense to everyone.
Family room decoration decoration construction contract
The Employer (hereinafter referred to as Party A):
ID number:
residence:
contact number:
phone number:
Contractor (hereinafter referred to as Party B):
ID number:
residence:
contact number:
phone number:
In accordance with the "People's Republic of China Contract Law" and other relevant laws and regulations, combined with the characteristics of Beijing's family room decoration, Party A and Party B, on the basis of equality, voluntariness, and consensus, will contract Party B to contract Party A's family room decoration. Relevant matters of the renovation project (hereinafter referred to as the project) have reached the following agreement:
I. Project Overview
1. construction place:
2. Project decoration area:
3. Project type:
4. Project content and practices: See the project content and budget (Annex 1), decoration process requirements (Annex 3).
5. Project contracting, adopting Party B's contracting work, including construction tools and equipment, and Party A's provision of construction materials.
6. Construction deadline:
Completion date:
7. Contract price:
The construction cost of this contract is (RMB): Yuan amount Capitalization:
The quoting quotation is based on the reference price of the Beijing Home Decoration Project, based on the rules of economic operation at regular times, and both parties agree in the contract based on the principle of high quality and preferential price. The quotation of the contract shall be compiled with the material quality standards and the system of safety and security as the basis for the project price.
II. Project supervision If this project implements project supervision, Party A shall sign a "project supervision contract" with the engineering supervision company approved by the construction administrative department, and shall supervise the engineer's name, unit, contact information and the responsibility of the project supervision engineer. Inform Party B, etc.
III. Construction Drawings The construction drawings shall be entrusted by Party A to design and provide construction drawings in triplicate. Party A shall hold one copy and Party B shall hold two copies.
Fourth, the work of Party A
1. Three days before the start of construction, conditions must be created for Party B's admission to construction so as not to affect the construction.
2. Provides free water, power and winter heating during construction.
3. Responsible for handling the start-up procedures of the house property department and related expenses that should be paid by the owner.
4. Observe the rules and regulations of the property management department.
5. Responsible for coordinating the relationship between the on-site construction team and the neighborhood.
6. Participate in the supervision of the construction progress of the project quality, participate in acceptance of engineering materials, inspection and acceptance of concealed projects, and completion acceptance.
V. Work of Party B
1. During the construction, the safety construction operation code, fire prevention regulations, construction specifications and quality standards shall be strictly implemented, and the contract shall be completed on schedule.
2. Do not disturb people or pollute the environment. Do not engage in decoration activities such as knocking, chiseling, creating, drilling, etc. that generate noise during the period from 12:00 to 14:00, 18:00 to 8:00 the next day.
3. As a result of the decoration and decoration construction, the pipelines of neighboring residents are blocked, leaked, water stopped, and power cuts, etc., and Party B shall be responsible for repairs and losses.
4. Responsible for the protection of finished furniture, equipment, and furnishings retained at home.
5. Ensure the smooth flow of indoor and sewer pipes and the cleanliness of bathrooms.
6. Ensure the cleanliness of the construction site, clean the construction site after daily completion, and remove the garbage to the designated place of the property.
7. Provide Party A with written materials including various standards, specifications, calculations, and reference prices involved in the signing and implementation of this contract.
Sixth, the project changes in the construction period of the contract agreed project content, if both need to change, both parties should agree. The parties to the contract jointly sign a written change agreement and adjust the related engineering fees and periodicities. The engineering change order is used as the basis for the completion settlement and the extension of the construction period.
Seven, material supply
1. Party B shall provide Party A with a list of required materials for purchase within five days in advance. Party A shall promptly purchase materials for use by the construction team within four days. Both parties shall bear their own responsibility for delaying the construction period and economic losses.
2. Without the consent of Party A, Party B may not purchase materials on its own. If it has been purchased, Party A has the right to refuse to use it and may refuse to pay for the materials.
3. Party B shall purchase materials at the building materials supply point designated by Party A and issue an official invoice.
4. Party B shall accept the quality of the building materials purchased by Party A. It is found that quality problems should be promptly raised to Party A and have the right to refuse to use it. If Party A insists on using it, Party B shall request Party B in writing and bear the loss caused by the quality of the material.
5. Party B shall help Party A to receive the goods and check the accuracy of the quantity and accessories.
6. Party B shall do a good job of keeping the materials, and it is forbidden for people to enter the site.
7. Without Party A's permission, Party B may not carry any building materials to go out. If such phenomena are found, the price of materials shall be doubled from the labor cost.
8. The Party A materials shall be sent downstairs to the site where the project is located. Any construction personnel of Party B shall be carried unconditionally.
VIII. Delay in construction period
1. For the delay in the date of completion due to the following reasons, after Party A confirms, the construction period shall be postponed: the quantity of the project changes; the force majeure; Party A agrees with the other circumstances of the extension of the construction period.
2. As Party B's liability cannot be completed on time, the construction period will not be postponed. Party B shall bear the cost of rework due to Party B's reasons for the quality of the project. The construction period will not be postponed.
3. Due to the delay of the construction period due to Party B's reasons, for each delay of one day, Party A shall compensate Party A for losses in accordance with 2% of the total construction costs.
Nine, quality standards
1. The interior pollution control of interior decoration shall be strictly implemented in accordance with the standards of the "Guidelines for Indoor Environmental Pollution Control of Civil Building Projects" (GB50325-2001).
2. The construction quality of this project is carried out according to "Beijing Quality Inspection Standard for Family Room Decoration Project" (DBJ/T01-43-2000).
3. Upon completion acceptance, the two parties disputed the project quality and indoor air quality, and applied for a professional inspection unit approved by the construction administrative department of Beijing Municipality and the quality and technical supervision department to certify the project quality and indoor air quality. The costs associated with the certification process are borne by the responsible party.
X. Project acceptance and warranty
1. In the construction process, joint inspection and acceptance of the project quality is carried out in the following stages:
(1) Material acceptance;
(2) Hidden project acceptance;
(3) Completion acceptance.
2. After the completion of the project, Party B informs Party A of acceptance.
3. Before both parties perform the final acceptance, Party B shall be responsible for the protection of all the safety of the finished project and the site of the project.
4. The warranty period for the interior decoration works under the normal conditions of use shall be two years from the date of acceptance of the completion of the project. The warranty period for the anti-leakage project for kitchens and toilets with waterproof requirements shall be five years.
XI. Construction payment methods
1. After the signing of the contract takes effect, Party A will pay the construction fee to Party B according to the contract in the contract:
Payment Times Payment Time According to the project payment rate The amount payable The first time the worker and the material enter the site The second time the progress of the project is more than half The third time the completion acceptance is passed
2. More than half of the progress of the project means: the end of woodworking production; the end of walls, floor tiles and ceilings; the leveling of the wall ends; and the completion of the hydropower reform.
3. The project money shall be settled according to the actual amount of the project.
4. After the construction funds are fully settled, Party B issues an official invoice to Party A as the main project certificate.
XII. Liability for breach of contract
1. If a party fails to perform the contractual obligation to the other party in accordance with the contract, it shall bear the liability for compensation; if the party is punished for violating the relevant laws and regulations, the ultimate responsibility shall be borne by the responsible party.
2. If one party cannot continue to perform the contract, it shall promptly notify the other party and the responsible party shall bear the loss caused by the cancellation of the contract.
3. Party A did not pay the third or fourth construction payment according to the contractual deadlines without justified reasons, and Party B paid Party B a penalty of 2% of the contractual cost of the contract for each delay.
4. As Party B’s responsibility leads to unqualified project quality and indoor air quality, Party B shall perform rework repair, comprehensive treatment and compensation according to the following agreement:
(1) Party B must perform thorough rework to repair the site where the quality of the project is not qualified. The delayed payment of the project due to rework is regarded as the delay of the same project. On each delay day, Party B shall pay Party B the liquidated damages of 2% of the construction cost of the contract.
(2) For unqualified indoor air quality, Party B must carry out comprehensive management. Due to governance, delayed delivery of the project is regarded as a delay in the same project. For each delay of one day, Party B shall pay Party B the liquidated damages of 2% of the contract's construction cost.
(3) If the indoor air quality still fails to meet the standard, Party B shall return the full price of the project of Party A's contract.
XIII. Dispute Resolution Methods In case of disputes arising under this contract, both parties shall negotiate or apply to the consumer association for mediation, consultation, or mediation to resolve the matter. They shall file a lawsuit in the people’s court where the project is located and ask the people’s court for a ruling.
XIV. Labor Management
1. Before the commencement of the work, Party B shall provide Party A with a copy of all construction personnel's ID cards.
2. Without the permission of Party A, non-construction workers may not spend the night on site.
3. Party A shall handle the community access documents for Party B in time and pay relevant fees.
4. Party B shall have all documents for temporary stay in Beijing. The relevant losses caused by incomplete documents shall be borne by Party B itself.
5. Party B designated the site responsible person for the site and the replacement person in charge.
6. Party B shall not arbitrarily change construction workers without the consent of Party A.
7. Without Party A's consent, Party B shall not suspend or complete the work under any circumstances.
15. Construction Machinery
1. Party B brings the necessary tools for construction and guarantees the safety and good use of the tools. Party B shall bear the cost of tool maintenance.
2. The consumables (such as drills, saw blades, etc.) generated by the tool are borne by both parties A and B by 50%.
16. Site Management on Site
1. The use of naked flames is prohibited on site.
2. Smoking is prohibited on site.
3. Paint materials must be placed separately from other materials.
17. Supplementary Provisions
1. This contract is made in two copies and will become effective after being signed by Party A and Party B.
2. The project shall not be subcontracted after signing this contract.
3. Both parties may make changes or supplements to this contract in written form. However, if the change or supplement unreasonably reduces or exempts the responsibilities that Party B should assume from this contract, this contract shall still prevail.
4. If the performance of the contract or the cause of the loss is affected due to the fact that it cannot be imputable and the parties have caused the loss, both parties shall settle the matter in accordance with the principle of fairness.
5. After the completion of this contract, it will be automatically terminated.
18. Other matters
1. Party B shall check the material quality and construction quality of the construction site; Party B shall use the materials provided by Party B before inspection.
2. Party B shall notify Party A of acceptance 48 hours in advance after the completion of the following key processes. After passing the inspection, Party B may proceed with the next process:
A, material approach
B. Hidden project
C. Waterway and Circuit Reconstruction
D. Waterproofing and water-blocking experiments
E, joinery substrate engineering
F, panel, wood line, solid wood cover
G, primer, topcoat
H, wall, top surface treatment
I. Suspended ceiling keel panel
J, all parts of the plate
K, Mid-term acceptance of the project
L. Overall acceptance of the project.
The above sub-projects have not been accepted by Party A, and Party B has carried out the construction of the next procedure without authorization. Therefore, Party B shall be responsible for the loss of work materials.
3. The main materials and quantities provided by Party B (including various plates, keels, water and electricity materials, paints, cement, plastics, paints, putty powder, plaster lines, etc.) must be consistent with the material brands stated on the list of materials attached to this contract. And notify Party A to verify it when entering the market. Party B shall present to party A relevant proofs of the purchase of materials (invoices or shopping papers or proof of company's unified supply), environmental protection certificates, warranty certificates, sources of materials, etc. Party A shall have the right to verify the authenticity of the materials with the manufacturer or distributor. If it is found that the materials provided by Party B are counterfeit products or products that do not comply with national, local, and relevant ministry standards and regulations, Party B must promptly replace the products agreed in the contract or other qualified products of the same price recognized by Party A and follow the contract. The double price of the market price of the agreed materials will compensate Party A; if Party B can prove that the legally recognized evidence fully proves that it is due to the responsibility of the supplier, Party A can appropriately reduce the amount of compensation required according to the specific circumstances, and Party B can supply the materials. The company pursues corresponding responsibilities. For the part that has been used for construction, Party A has the right to request Party B to dismantle and redo the work. The expenses incurred by Party B shall be borne by Party B.
4. Special trades such as electricians and plumbers are required to hold relevant certificates and be examined before they can go on duty.
5. The project change must have a written agreement, detailing the quantity and price of the change and signing the approval of both parties can be used as a basis for settlement.
6. Execution of Construction Process Standards <GB50327-2001> Execution of Project Acceptance Standards <GB50210-2001> Implementation of Environmental Protection Standards <GB50325-2001> Contractors who do not meet this standard shall bear compensation for non-compliance projects.
7. The decoration materials provided by Party A arrive at the scene, and Party B can only use it after passing the acceptance of quality and quantity. Once it is used, it shall be deemed as qualified. The resulting construction quality problems shall be the full responsibility of Party B. If Party B can prove after the fact that the quality problem is indeed caused by the unqualified material provided by Party A, and the quality problem cannot be discovered through conventional means such as observation, hand touch, and ruler measurements, the parties A and B shall bear 50 %Responsibility.
8. Party B is obliged to properly maintain the materials provided by Party A. Party B shall be responsible for compensation if any damage or loss occurs. Party B must clean up and collect the garbage generated during the renovation process and place it in the designated place of the property department.
9. During the construction process, Party B shall abide by the construction safety operation regulations, be responsible for safety management at the construction site, take the necessary safety protection and fire prevention measures, ensure the safety of personnel, and avoid the loss of Party A's houses and other properties. Party B shall not occupy public space during construction and shall not damage the facilities in public areas. All civil and criminal liabilities incurred by Party B's construction workers during the construction and maintenance period shall be borne by Party B.
10. If Party A wishes to increase the project or does not increase the construction cost due to design mistakes or intentional missing items, Party A needs to increase the price of the project with reference to the single quotation of the contract.
11. During the construction period, Party A believes that Party B's construction personnel are not entitled to the decoration work due to the level of workmanship, work attitude, character, etc., and have the right to request Party B to replace the construction personnel.
12. During the warranty period, the owner informs the construction party that it needs repairs. The construction party must arrive at the site within 24 hours. If the repair is caused due to the construction quality of Party B or the quality of the materials provided, the party cannot provide a solution within 48 hours after Party A writes the repairs. Party A can solve the problem on its own, and all costs incurred by Party A are borne by Party B. If, during the warranty period, an accident involving endangerment of personal safety or other property safety involving water, electricity, gas, etc., arises because of engineering quality problems, Party A may first deal with it and Party B shall pay Party B for all reasonable expenses it has incurred. During the warranty period, Party B shall bear the responsibility of replacement if it is found to have serious deformation or repair that will affect the overall appearance.
Entrance decoration children's room decoration decoration interior decoration door price home decoration paint bathroom door bathroom ceiling material bathroom design bathroom waterproof price bathroom ceiling overall bathroom public bathroom bathroom waterproof bathroom floor tile
NON-Phthalate Plasticizer include Epoxy Fatty Acid Methyl Ester (EFAME) and Epoxidized Soybean Oil (ESO), they are made of plant oil, Soybean Oil, vegetable acid oil. They are mainly used to replace the primary plasticizer in PVC products, like the DOP, DINP, DBP, DOTP, ATBC, and other plasticizer. Jingu`s non-phthalate plasticizer has offered a safe alternative to phthalates and is commonly found in children`s toys and other articles designed for children.
Application: Our NON-Phthalate Plasticizer has excellent compatibility with PVC resin. They are widely used in PVC calendering film, PVC foaming artificial leather, wire and cables, disposable PVC gloves, children toys, infusion tube, food packaging film, medical equipments and culture products.
Jingu`s non-phthalate plasticizer serves in markets from flooring to wire and cable, flexible PVC, and more. And also for sensitive grade areas like toys and child care, food contact supplies, and medical applications. Warmly welcome to visit our Factory. If you have any questions, please contact with us directly. Samples will be available for testing.
NON-Phthalate Plasticizer
Non Phthalate Plasticizer,Non Phthalate Plasticizer Pvc,Eastman Non-Phthalate Plasticizer,Non Phthalate Plasticizers For Pvc
Hebei Jingu Plasticizer Co.,Ltd , http://www.hebei-jingu.com